Topic
Delay Claims
92 published works
Florida Construction Legal Updates
CREDIBILITY MATTERS…EVEN IN DELAY CLAIMS
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private…
Government Contracts Featured Insights
Proving Excusable and Compensable Delays in Termination for Default Appeals
Contractors may encounter delays when performing government contracts that increase the time or cost of performance. Contractors typically bear the risk of such increases for delays that are avoidable or…
BuildSmart
10th Circuit Affirms Verdict for Engineering Firm in AECOM-Flatiron Dispute
The U.S. Court of Appeals for the 10th Circuit has affirmed the jury verdict and judgment in favor of engineering firm AECOM Technical Services in its long-running dispute with the…
Claims & Sustains
The Clock Is Still Ticking — Claims Timeliness Across the Boards and at the COFC
By Sarah Barney, Zachary F. Jacobson
https://www.youtube.com/watch?v=tNHcloyHVfc Seyfarth associates Zach Jacobson and Sarah Barney reunite to discuss timeliness issues - this time in contract claims and claim appeals.
BuildSmart
Yes, Damages for Delay: Court Permits Delay Damage Claim to Proceed
A federal court in upstate New York is permitting a subcontractor's delay claim to proceed notwithstanding a "no damages for delay" provision in the subcontract. The case, The Pike Company, Inc.…
Florida Construction Legal Updates
…MORE ON DELAY CLAIMS AND THE BURDEN OF PROOF SUBSTANTIATING DELAY
How about some more on DELAY claims and the burden of proof substantiating delay. Delay claims can no doubt be complex – factually and legally. They warrant expert opinions further…
Tort Talk
Delay Damages Claim Denied Based on Technical Defect to Delay Damages Motion
In a case of first impression in the case of Arreguin v. Kinsing, No. 889 EDA 2023 (Pa. Super. Nov. 5, 2024 Stabile, J, Dubow, J., and Sullivan, J.) (Op.…
Florida Construction Legal Updates
THERE ARE CONSEQUENCES TO EXECUTED DOCUMENTS SUCH AS THE ACCORD AND SATISFACTION DEFENSE
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is…
Global Policy Watch
You Can’t Always Get What You Want: ASBCA Channels Rolling Stones and Awards Contractor $4.9 Million in Delay Damages
By Homer La Rue, Daniel Russell Jr.
A recent decision by the Armed Services Board of Contract Appeals found the Navy liable to a commercial crane manufacturer for delay damages. In Konecranes Nuclear Equip. & Servs., LLC,…
Inside Government Contracts
You Can’t Always Get What You Want: ASBCA Channels Rolling Stones and Awards Contractor $4.9 Million in Delay Damages
By Daniel Russell Jr., Homer La Rue
A recent decision by the Armed Services Board of Contract Appeals found the Navy liable to a commercial crane manufacturer for delay damages. In Konecranes Nuclear Equip. & Servs., LLC,…